Team Contractors, L.L.C. et al v. Waypoint NOLA, L.L.C. et al
| Team Contractors, L.L.C. |
| Waypoint NOLA, L.L.C., HC Architecture, L.L.C. and KLG, L.L.C. |
| 2:2016cv01131 |
| February 5, 2016 |
| US District Court for the Eastern District of Louisiana |
| New Orleans Office |
| Out of State |
| Susie Morgan |
| Joseph C. Wilkinson |
| Other Contract |
| 28 U.S.C. ยง 1332 |
| None |
Follow case documents by RSS
Available Case Documents
The following documents for this case are available for you to view or download:
| Document Text |
|---|
Filing
690
ORDER & REASONS 685 ADOPTING REPORT AND RECOMMENDATIONS: IT IS ORDERED that Defendant's 675 motion to fix attorneys' fees and costs in GRANTED IN PART and DENIED IN PART. Signed by Judge Susie Morgan on 3/30/2023.(pp)
|
|
Filing
668
ORDER ADOPTING 665 , 666 REPORT AND RECOMMENDATIONS: IT IS ORDERED that Plaintiff Team Contractors, LLC's 661 motion to stay is GRANTED. IT IS FURTHER ORDERED that Defendant Waypoint NOLA, LLC's 635 motion to fix attorneys' fee s and costs be DISMISSED WITHOUT PREJUDICE to refiling, if appropriate, no later than 28 days after the pending appeal has been resolved by issuance of mandate by the United States Court of Appeals for the Fifth Circuit, at which time Waypoint must request and provide evidence of any additional attorneys' fees it seeks. Signed by Judge Susie Morgan on 12/14/2021.(pp)
|
|
Filing
650
ORDER AND REASONS: IT IS ORDERED that Defendant Waypoint NOLA, L.L.C.'s 635 Motion to Fix Attorneys' Fees and Costs is GRANTED insofar as the Court finds Waypoint is the prevailing party under the Prime Contract entitled to recover its a ttorneys' fees, experts' fees, and costs. The motion is REFERRED to the Magistrate Judge for determination of the amount of attorneys' fees, experts' fees, and costs owed. IT IS FURTHER ORDERED that Plaintiff Team Contractors, L.L.C.'s 644 Motion to Declare Plaintiff the Substantially Prevailing Party is DENIED. Signed by Judge Susie Morgan on 9/29/2021.(pp) (NEF: Magistrate Judge Section 2)
|
|
Filing
632
ORDER ADOPTING REPORT AND RECOMMENDATIONS 623 - For the reasons herein, the Court APPROVES the magistrate judge's report and recommendation and ADOPTS it as its own. IT IS ORDERED that Plaintiff's motion for attorneys' fees and cos ts is DISMISSED WITHOUT PREJUDICE to refiling, subject to the Court's accompanying order preserving Plaintiff's claims and extending the time in which Plaintiff must file its renewed motion for attorneys' fees and costs to twenty-eight days after entry of the mandate by the United States Court of Appeals for the Fifth Circuit resolving the pending appeal. Signed by Judge Susie Morgan.(bwn)
|
|
Filing
618
ORDER AND REASONS - IT IS ORDERED that 601 motion for judgment as a matter of law or alternatively for a new trial, filed by Defendant Waypoint NOLA, L.L.C. under Rule 50(b) of the Federal Rules of Civil Procedure, be and hereby is DENIED. Signed by Judge Susie Morgan. (bwn)
|
|
Filing
588
ORDER AND REASONS denying 563 Motion for Leave to Contact a Juror. Signed by Judge Susie Morgan on 5/21/2019. (sbs)
|
|
Filing
530
ORDER AND REASONS denying 502 Motion to Strike Jury as stated herein. Signed by Judge Susie Morgan on 4/8/2019. (tsf)
|
|
Filing
519
ORDER AND REASONS - For the reasons herein, IT IS ORDERED that the motions in limine, filed by Defendant Waypoint NOLA, L.L.C., be and hereby are GRANTED IN PART and DENIED IN PART. IT IS FURTHER ORDERED that at the second trial in this matter, Tea m will not be permitted to recover design-related acceleration damages. Team will be permitted to seek contractual damages with respect to change orders unrelated to design errors and contractual interest with respect to Waypoint's payment of July 10, 2017. The parties will be permitted to introduce evidence relevant to these claims. Signed by Judge Susie Morgan. (bwn)
|
|
Filing
488
ORDER AND REASONS - The 451 motion for summary judgment filed by Defendant Waypoint NOLA, L.L.C. is DENIED. FURTHER ORDERED that Defendant Waypoint NOLA, L.L.C.'s request for oral argument on its motion for summary judgment is DENIED AS MOOT. Signed by Judge Susie Morgan on 3/20/19. (sbs)
|
|
Filing
429
ORDER AND REASONS - IT IS ORDERED that the 423 Motion to Amend the Court's Order of September 6, 2018 pursuant to 28 U.S.C. § 1292(b) filed by Defendant Waypoint NOLA, L.L.C. ("Waypoint") be and hereby is DENIED. IT IS FURTHER ORDERED that Waypoint's 424 Request for Oral Argument on its Motion to Amend be and hereby is DENIED. Signed by Judge Susie Morgan. (bwn)
|
|
Filing
420
ORDER AND REASONS - IT IS ORDERED that the 372 Motion to Amend Judgment filed by Plaintiff Team Contractors, L.L.C. ("Team"), construed as a motion for a new trial on its breach of contract claim against Defendant Waypoint NOLA, L.L.C. ("Waypoint"), be and hereby is GRANTED. IT IS FURTHER ORDERED that the Court's 370 judgment for Defendant Waypoint on Plaintiff Team's breach of contract claim be and hereby is VACATED. IT IS FURTHER ORDERED that Defendant Waypoint's 373 Motion for Attorney's Fees be and hereby is DENIED AS MOOT. Signed by Judge Susie Morgan. (bwn)
|
|
Filing
323
ORDER denying 321 Motion to Amend/Correct 320 Order and Reasons granting 307 Motion Addressing Waypoint's Rights to Pursue Statutory Penalties Under LA. R.S. 22:1973. Signed by Judge Susie Morgan. (bwn)
|
|
Filing
320
ORDER AND REASONS granting 307 Motion Addressing Waypoint's Rights to Pursue Statutory Penalties Under LA. R.S. 22:1973. Waypoint NOLA, L.L.C.'s claim for statutory penalties pursuant to La. R.S. 22:1973 is dismissed with prejudice. Signed by Judge Susie Morgan. (bwn)
|
|
Filing
284
ORDER AND REASONS: ORDERED that Defendants' 129 Motion for Partial Summary Judgment on Team's total cost calculations is hereby DENIED. FURTHER ORDERED that Defendant's 230 Motion in Limine to preclude evidence of Team's total cost claims and lost profits claims is hereby DENIED. Signed by Judge Susie Morgan on 10/5/2017. (clc)
|
|
Filing
275
ORDER AND REASONS denying 124 Motion for Partial Summary Judgment on Team Contractors, LLC's claim for lost profits. Signed by Judge Susie Morgan on 10/2/2017. (clc)
|
|
Filing
267
ORDER AND REASONS denying 118 Motion for Partial Summary Judgment on Waypoint's claim for lost profits. Signed by Judge Susie Morgan on 9/29/2017. (clc)
|
|
Filing
255
ORDER AND REASONS denying 119 Motion for Partial Summary Judgment on Team Contractors, LLC's claim for lost profits. Signed by Judge Susie Morgan on 9/28/2017. (clc)
|
|
Filing
247
ORDER AND REASONS denying Waypoint's 123 Motion for Partial Summary Judgment regarding HCA and KLG's Liability. Signed by Judge Susie Morgan on 9/22/2017. (tsf)
|
|
Filing
115
ORDER AND REASONS GRANTING IN PART AND DENYING IN PART 93 Motion to Compel; 105 Motion for Protective Order as set forth in document. Signed by Magistrate Judge Joseph C. Wilkinson, Jr on 7/28/2017. (my)
|
|
Filing
77
ORDER AND REASONS denying Plaintiff's 53 Motion for Partial Summary Judgment, as stated herein. Signed by Judge Susie Morgan on 2/13/2017. (cg)
|
Use the links below to access additional information about this case on the US Court's PACER system. A subscription to PACER is required.
Access this case on the Louisiana Eastern District Court's Electronic Court Filings (ECF) System
- Search for Party Aliases
- Associated Cases
- Attorneys
- Case File Location
- Case Summary
- Docket Report
- History/Documents
- Parties
- Related Transactions
- Check Status
Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.
