Jamison Electric, LLC v. Fidelity and Deposit Company of Maryland et al
Jamison Electric, LLC |
Fidelity and Deposit Company of Maryland and Hankins Construction Company |
Hankins Construction Company |
Jamison Electric, LLC |
4:2012cv01746 |
September 27, 2012 |
US District Court for the Eastern District of Missouri |
St. Louis Office |
St. Louis - County |
Catherine D. Perry |
Contract: Other |
28 U.S.C. ยง 1331 Fed. Question |
Defendant |
Available Case Documents
The following documents for this case are available for you to view or download:
Document Text |
---|
Filing 91 MEMORANDUM AND ORDER - IT IS HEREBY ORDERED that defendant's motion to alter or amend the judgment [#88] is granted in part. The award of prejudgment interest is reduced by $3520.13. An amended judgment accompanies this order. IT IS FURT HER ORDERED that plaintiff's motion for bill of costs [#87] is granted in part. The Clerk of Court shall tax the following costs in favor of Jamison Electric, LLC and against Hankins Construction Co.: Fees of the Clerk $97 Fees for transcripts necessarily obtained $3,251.70 TOTAL TAXABLE COSTS $3,348.70. Signed by District Judge Catherine D. Perry on April 13, 2015. (MCB) |
Filing 80 FINDINGS OF FACT AND CONCLUSIONS OF LAW. (see document for details) After reviewing all the evidence, I have concluded that Hankins breached the subcontract by not paying Jamison the contract balance, plus two items of extra work, and that Jamison breached the subcontract by failing to complete certain items of work it was obligated to do. I have also concluded that Fidelity is not liable under the payment bond or for vexatious refusal to pay because Jamison instituted suit too early and was t herefore not in compliance with the terms of the bond. After totaling the parties' obligations, I have determined that Jamison's damages against Hankins, including prejudgment interest, amount to $84,593.06. I will enter judgment in J amison's favor in that amount. Hankins will bear all taxable costs of this action. I will enter judgment in Fidelity's favor on Jamison's claims of breach of the payment bond and vexatious refusal to pay. I will also require that Jamison indemnify Hankins and Fidelity for any claim made by Centrex. Judgment is entered separately. Signed by District Judge Catherine D. Perry on 12/31/2014. (CBL) |
Filing 42 MEMORANDUM AND ORDER re: 37 MOTION for Partial Summary Judgment filed by Defendant Hankins Construction Company. IT IS HEREBY ORDERED that defendant Hankins Construction Company's motion for partial summary judgment [#37] is GRANTED. Signed by District Judge Catherine D. Perry on December 16, 2013. (MCB) |
Filing 32 MEMORANDUM AND ORDER re: 26 MOTION to Dismiss :Jamison Electric's Delay/Hindrance/Acceleration Claim filed by Defendant Hankins Construction Company. IT IS HEREBY ORDERED that defendant Hankins Construction Company's motion to dismiss [#26] is denied. Signed by District Judge Catherine D. Perry on July 22, 2013. (MCB) |
Use the links below to access additional information about this case on the US Court's PACER system. A subscription to PACER is required.
Access this case on the Missouri Eastern District Court's Electronic Court Filings (ECF) System
- Search for Party Aliases
- Associated Cases
- Attorneys
- Case File Location
- Case Summary
- Docket Report
- History/Documents
- Parties
- Related Transactions
- Check Status
Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.